Are you looking for a free subcontractor agreement template that will iron out the details of your contractor-subcontractor relationship and to seal it in writing? Then grab your free contract here.
Let's take a closer look at a few of the must-know details in our free subcontractor contract:
1. Description of Work - No two work projects are exactly alike so we have given you extra room to customize this section of our sub contractor agreement and make it your own. You can choose to be brief and just give a general scope of work... or you can dive deep into the details such as specifying the exact paint brand and color for a painting job.
2. Payment(s) for Work - There are two popular ways for a subcontractor to be paid: First we have the single lump-sum payment that is often favored for smaller work projects.
For more complex or longer projects, it's quite common to see the payment being dished out in several installments as work progresses (progress payments) with a final payment waiting at the end of the work project.
4. Work Delays - While our free subcontractor agreement form has laid down the details for work delays due to natural calamities, you may want expand it further to cover man-made mischief as well - such as labor strikes, riots, vandalism, explosions, wars and other causes beyond the subcontractor's reasonable control.
*Make sure this sub contractor contract complies with your local real estate laws before using it. If you have any doubts, you can ask a real estate lawyer online.
This Agreement is made between the Contractor _________________________ of address
___________________________________________________________________________ and the Subcontractor _________________________ of address
___________________________________________________________________________ on this date ______________.
The Contractor has entered into a contract with the Owner _________________________ of address
___________________________________________________________________________ on this date ______________.
1. DESCRIPTION OF WORK:
The Subcontractor agrees to provide all labor, material, equipment and perform all work described as follows:
___________________________________________________________________________
___________________________________________________________________________
___________________________________________________________________________
___________________________________________________________________________
The above-described work shall be performed in accordance with the Agreement Between Owner and Contractor, and in accordance with the following plans, specifications and documents:
___________________________________________________________________________
___________________________________________________________________________
The above-described work shall be performed at the following location:
___________________________________________________________________________
All work under this agreement between contractor and subcontractor shall be completed in a workmanship-like manner and in compliance with all building codes and other applicable laws.
The Contractor also warrants all work performed, and agrees to remedy any defects resulting from faulty materials or workmanship for a period of _____ months after work completion.
2. PAYMENT(S) FOR WORK:
The Contractor agrees to pay the Subcontractor for the performance of the above-described work the sum of $ _______________ in the following manner:
{ Describe Payment Method and Timing }
3. WORK SCHEDULE:
The date(s) of commencement and completion shall be as follows (choose one):
[ ] The work to be performed under this agreement shall begin on _______________ and shall be fully completed on or before _______________.
[ ] The work to be performed under this agreement shall begin on _______________, and various portions of the above-described work shall be completed on or before the following dates:
{ Describe Work Portions and Completion Dates }
4. WORK DELAYS:
In the event that the work is delayed due to the neglect of the Subcontractor, the Subcontractor agrees to pay the Contractor the sum of $ _______________ per day as liquidated damages until the work is completed.
In the event that the work is delayed due to the neglect of the Contractor, acts of God, fire, flood or any unavoidable natural calamities, the time for completion of the work shall be extended by the same period as the delay occasioned by any of the aforementioned causes.
In the event that the Subcontractor encounters hidden rocks, ground water, underground structures, utilities or other unknown concealed conditions, the Subcontractor shall stop work immediately and inform the Contractor of such concealed conditions in writing. The payment for work and work schedule under this sub contractor agreement shall be adjusted accordingly in writing.
5. WORK CHANGES:
If the Owner requests or requires any change that limits or expands the work to be performed under the original Agreement Between Owner and Contractor, the Subcontractor shall accept such change orders.
Any resulting increases or decreases in the sum of payment for work shall be in writing, mutually agreed to and signed by both parties. If both parties are not able to agree on the price adjustment for a change order, the Subcontractor shall proceed with the change order as scheduled and the price adjustment dispute shall be submitted for arbitration within 30 days of the change order being issued.
6. INSURANCE:
The Subcontractor shall obtain adequate insurance against any claims or liabilities arising from the performance of this subcontractor agreement. This includes but it is not limited to general commercial liability insurance, workmen's compensation insurance and automobile liability insurance. The Subcontractor shall maintain such insurance for the entire work duration.
7. INDEMNITY:
The Subcontractor agrees to indemnify, defend and hold the Contractor harmless from all claims, losses, expenses, fees (including attorney fees), costs, settlements and judgments arising from the performance of this subcontractor contract.
8. ARBITRATION:
Any dispute arising from the performance or non-performance of this agreement shall be resolved at the request of either party through binding arbitration, and judgment on the award may be entered in any court having jurisdiction thereof. The prevailing party in any arbitration concerning this subcontractor agreement shall be entitled to reasonable attorneys' fees.
9. ASSIGNMENT:
Assignment for the above-described work shall be as follows (choose one):
[ ] The Subcontractor shall not have the right to assign any rights or interest under this sub contractor agreement without the written consent of the Contractor. The Subcontractor shall not assign any sums due, or to become due to him/her under the terms of this agreement.
[ ] The Subcontractor shall have the right to assign any work under this agreement or to subcontract any portions of it without the consent of the Contractor.
10. ADDITIONAL TERMS AND CONDITIONS:
___________________________________________________________________________
___________________________________________________________________________
___________________________________________________________________________
___________________________________________________________________________
___________________________________________________________________________
Contractor Name: _________________________
Contractor Signature: _________________________
Date: _______________
Subcontractor Name: _________________________
Subcontractor Signature: _________________________
Date: _______________